Supreme Court of India
Batliboi Environmental Engineers Limited v. Hindustan Petroleum Corporation Limited and Another
INSC stands for INDIAN SUPREME COURT. A neutral citation scheme assigned by the Court itself, so a judgment can be cited without depending on a commercial law reporter. INSC is the neutral citation scheme assigned by the Supreme Court, so a judgment can be cited without depending on a commercial law reporter.
What the Court ordered
In view of the aforesaid discussion, the appeal is dismissed without any order as to costs.
Judgment, page 36
From the headnote
Issue for consideration: Whether the Division Bench of the High Court was justifi ed in allowing the appeal fi led by the respondents u/s. 37 of the Arbitration and Conciliation Act, 1996, and thereby setting aside the arbitral award. Arbitration and Conciliation Act, 1996 – s. 37 – Arbitral award – Interference with – Award of turnkey contract to the appellant by the respondents for a contract value to be completed within stipulated period – Delay in project completion which was extended, and thereafter the appellant abandoned the work, only 80% of the work was completed – Matter proceeded for
Authorities it was built on
- 2019 Ssangyong Construction Co. Ltd. v. National Highways Authority of India (nhai)
- 2019 Mmtc Ltd. v. M/s Vedanta Ltd.
- 2014 Oil & Natural Gas Corporation. Ltd. v. Western Geco International Ltd.
- 1998 Kuldeep Singh v. Commissioner of Police and Ors.
- 2019 Gurmit Singh Bhatia v. Kiran Kant Robinson and Others
Sign in free to read it
- The full judgment, page by page, as published in the Supreme Court Reports
- The ratio: what the Court held, verbatim, with the page it sits on
- Every bench that relied on it, and every bench that argued against it
- Search every reported judgment, by party, citation or question
- Download the PDF, copy pinpoint citations ready for a filing
An email address, no password.