Supreme Court of India
Welspun Specialty Solutions Limited (formerly Known as Remi Metals Gujarat Ltd. v. Oil and Natural Gas Corporation Ltd.
INSC stands for INDIAN SUPREME COURT. A neutral citation scheme assigned by the Court itself, so a judgment can be cited without depending on a commercial law reporter. INSC is the neutral citation scheme assigned by the Supreme Court, so a judgment can be cited without depending on a commercial law reporter.
1 Supreme Court bench has cited this judgment.
From the headnote
Arbitration and Conciliation Act, 1996: ss. 37 and 34 – Appealable orders – Arbitral award – Sustainability of, under sect ion 37 – On facts, execution of contract wherein appellant was to supply pipes to the respondent-ONGC – During execution of contract, certain delays in meeting the obligations as requir ed under the contract – Deduction of certain amount by respondent as liqu idated damages from various bills submitted by the supplie r – Dispute before the arbitral tribunal – Arbitral tribunal proceeded to determine the actual damages, holding that the liquidated damages could not be
Authorities it was built on
- 2003 Oil & Natural Gas Corporation Ltd. v. Saw Pipes Ltd.
- 2014 Associate Builders v. Delhi Development Authority
- 1993 Renusagar Power Co. Ltd. Etc. v. General Electric Co. Etc.
- 2019 M/s. Dyna Technologies Pvt. Ltd. v. M/s. Crompton Greaves Ltd.
- 2014 Oil & Natural Gas Corporation. Ltd. v. Western Geco International Ltd.
Sign in free to read it
- The full judgment, page by page, as published in the Supreme Court Reports
- The ratio: what the Court held, verbatim, with the page it sits on
- Every bench that relied on it, and every bench that argued against it
- Search every reported judgment, by party, citation or question
- Download the PDF, copy pinpoint citations ready for a filing
An email address, no password.