Supreme Court of India
K.N. Sathyapalan (dead) by Lrs. v. State of Kerala and Anr.
INSC stands for INDIAN SUPREME COURT. A neutral citation scheme assigned by the Court itself, so a judgment can be cited without depending on a commercial law reporter. INSC is the neutral citation scheme assigned by the Supreme Court, so a judgment can be cited without depending on a commercial law reporter.
2 Supreme Court benches have cited this judgment.
From the headnote
Arbitration Act, 1940-s.17-Non-completion of work within stipulated time-Ex_tension of time on co_ndition that contractor not eligible to escalation costs for work done during extended period-Arbitrator allowing the claims on account of escalation costs-High Court setting aside the same holding that arbitrator had exceeded its jurisdiction in granting award-Justification of-Held, not justified as delay had occurred due to law and order problem at the work site which should have been avoided by the State Government. The appellant entered into an agreement with the Respondent-State whereby it
Where later benches applied it
- 2017 Assam State Electricity Board and Ors. v. Buildworth Pvt. Ltd.
- 2019 M/s. Dyna Technologies Pvt. Ltd. v. M/s. Crompton Greaves Ltd.
Of those, 1 relied on · 1 referred to
Sign in free to read it
- The full judgment, page by page, as published in the Supreme Court Reports
- Every bench that relied on it, and every bench that argued against it
- Search every reported judgment, by party, citation or question
- Download the PDF, copy pinpoint citations ready for a filing
An email address, no password.